Contract Type/Flowdowns
Tggri2147
AttachmentforFlowdownsExercise3.rtf
AWARD / CONTRACT
- THIS CONTRACT IS A RATED ORDER UNDER DPAS (15 CFR 350)
RATING
N
PAGE of PAGES
1
- CONTRACT (PROC. INST. IDENT.) NO. 3. EFFECTIVE DATE 4. REQUISITION / PURCHASE REQUEST / PROJECT NO.
FA1234-16-C-1000 See Section G
5. ISSUED BY CODE FA1234 6. ADMINISTERED BY (IF OTHER THAN ITEM 5) CODE
DEPARTMENT OF THE AIR FORCE
DCMA
SCD: C
- NAME AND ADDRESS OF CONTRACTOR (NO., STREET, CITY, COUNTY, STATE AND ZIP CODE)
ABC, INC.
123 ABC WAY
ANYWHERE, MD 20XXX
(301) 123-4567
- DELIVERY
FOB Origin Other (see below)
- DISCOUNT FOR PROMPT PAYMENT
N
- SUBMIT INVOICES
(4 COPIES UNLESS OTHERWISE SPECIFIED) TO
CAGE CODE 03MT8 FACILITY CODE THE ADDRESS SHOWN IN
ITEM
See Block 12
- SHIP TO / MARK FOR CODE 12. PAYMENT WILL BE MADE BY CODE FA8732 See Section F
EFT: T
13. AUTHORITY FOR OTHER THAN FULL AND OPEN COMPETITION 14. ACCOUNTING AND APPROPRIATION DATA
15A. ITEM NO 15B. SUPPLIES/SERVICES 15C. QUANTITY 15D. UNIT 15E. UNIT PRICE 15F. AMOUNT
See Section B
15G. TOTAL AMOUNT OF CONTRACT $5,790,000,000.00
16. Table of Contents
SEC
DESCRIPTION
PAGE(S)
SEC DESCRIPTION PAGE(S)
PART I - THE SCHEDULE
PART II - CONTRACT CLAUSES
Ö
A
SOLICITATION/CONTRACT FORM
1
Ö
I CONTRACT CLAUSES 62
Ö
B
SUPPLIES OR SERVICES AND PRICES/COSTS
2
PART III - LIST OF DOCUMENTS, EXHIBITS & ATTACHMENTS
Ö
C
DESCRIPTION/SPECS./WORK STATEMENT
34
Ö
J LIST OF ATTACHMENTS 114
Ö
D
PACKAGING AND MARKING
35
PART IV - REPRESENTATIONS AND INSTRUCTIONS
Ö
E
INSPECTION AND ACCEPTANCE
36
K REPRESENTATIONS, CERTIFICATIONS
Ö
F
DELIVERIES OR PERFORMANCE
38
OTHER STATEMENTS OF OFFERORS
Ö
G
CONTRACT ADMINISTRATION DATA
40
L INSTRS., CONDS., AND NOTICES TO
Ö
H
SPECIAL CONTRACT REQUIREMENTS
42
M EVALUATION FACTORS FOR AWARD
CONTRACTING OFFICER WILL COMPLETE ITEM 17 OR 18 AS APPLICABLE
17. Contractor’s Negotiated Agreement 18. Award (Contractor is not required to sign this document).
(Contractor is required to sign this document and return 1 copies to issuing office). Contractor agrees to furnish and deliver all items or perform all services set forth or otherwise identified above and on any continuation sheets for the consideration stated herein. The rights and obligations of the parties to this contract shall be subject to and governed by the following documents: (a) this award/contract, (b) the solicitation, if any, and (c) such provisions, representations, certifications, and specifications, as are attached or incorporated by reference herein. (Attachments are listed herein.)
Your offer on solicitation number including the additions or changes made by you which additions or changes set forth in full above, is hereby accepted as to items listed above and on any continuation sheets. This award consummates the contract which consists of the following documents: (a) the Government’s solicitation and your offer, and (b) this award/contract. No further contractual document is necessary.
19A. NAME AND TITLE OF SIGNER (TYPE OR PRINT) 20A. NAME OF CONTRACTING OFFICER
19 B . Name of Contractor 19C. Date Signed 20B. United States of America 20C. Date Signed
by (signature of person authorized to sign)
by (signature of Contracting Officer)
NSN
Qty Unit Price
ITEM SUPPLIES OR SERVICES Purch Unit Total Item Amount
0010
Noun: NETWORK ENTERPRISE SOLUTIONS
Contract type: J - FIRM FIXED PRICE
Descriptive Data:
The contractor shall provide a wide range of solutions to complete the requirements IAW the PWS of the basic contract (Section J, Atch 1).
PART I - THE SCHEDULE
SECTION C - DESCRIPTION/SPECS./WORK STATEMENT
SECTION C
C001 WORK DESCRIPTION/SPECIFICATION
PART I - THE SCHEDULE
SECTION C - DESCRIPTION/SPECS./WORK STATEMENT
SECTION C
The selected Contractor must provide 24x7x365 monitoring and operations services through an array of strategic tasks to ensure the availability and security of the network and remain responsive to the demands of the warfighters. This support will enable the USAF to maintain a tightly integrated, agile, defensible, survivable network capable of supporting highly distributed operations as well as an efficient and effective business enterprise. Specific requirements are in Section J-1.
[Note to UMUC BMGT 482 students: this attachment is not relevant to this assignment and is not actually provided.]PART I - THE SCHEDULE
SECTION D - PACKAGING AND MARKING
SECTION D
D001 PACKAGING REQUIREMENTS
PART I - THE SCHEDULE
SECTION D - PACKAGING AND MARKING
SECTION D
Specific requirements are in Section J-1.PART I - THE SCHEDULE
SECTION E - INSPECTION AND ACCEPTANCE
SECTION E
FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES
52.246-02 INSPECTION OF SUPPLIES -- FIXED-PRICE (AUG 1996)
52.246-03 INSPECTION OF SUPPLIES -- COST-REIMBURSEMENT (MAY 2001)
52.246-04 INSPECTION OF SERVICES -- FIXED-PRICE (AUG 1996)
52.246-05 INSPECTION OF SERVICES -- COST-REIMBURSEMENT (APR 1984)
52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001)
52.246-06 INSPECTION -- TIME-AND-MATERIAL AND LABOR-HOUR (MAY 2001) - ALTERNATE I (APR 1984)
52.246-15 CERTIFICATE OF CONFORMANCE (APR 1984)
52.246-16 RESPONSIBILITY FOR SUPPLIES (APR 1984)
E0 1 INSPECTION AND ACCEPTANCE AUTHORITY
PART I - THE SCHEDULE
SECTION E - INSPECTION AND ACCEPTANCE
SECTION E
Inspection and acceptance for all Contract and Exhibit Lines or Subline Items shall be accomplished by the Program Manager or PCO as identified in the CDRLS and Contract and Exhibit Lines or Subline Items.
PART I - THE SCHEDULE
SECTION F - DELIVERIES OR PERFORMANCE
SECTION F
NOTICE: The following contract clauses pertinent to this section are hereby incorporated by reference:
FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES
52.211-11 LIQUIDATED DAMAGES -- SUPPLIES, SERVICES, OR RESEARCH AND DEVELOPMENT (SEP 2000)
52.211-17 DELIVERY OF EXCESS QUANTITIES (SEP 1989)
52.242-15 STOP-WORK ORDER (AUG 1989)
52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)
52.247-34 F.O.B. DESTINATION (NOV 1991)
PART I - THE SCHEDULE
SECTION G - CONTRACT ADMINISTRATION DATA
SECTION G
G01 CONTRACTING AND ADMINISTRATIVE AUTHORITY
PART I - THE SCHEDULE
SECTION G - CONTRACT ADMINISTRATION DATA
SECTION G
The Procuring Contracting Officer (PCO) is the only person authorized to approve changes or modify the terms of the Schedule or clauses.
G02 ADMINISTRATIVE MATTERS
PART I - THE SCHEDULE
SECTION G - CONTRACT ADMINISTRATION DATA
SECTION G
- The address and telephone number of the PCO is: as stated on the cover page
- The ACO is: as stated on the cover page
- The contractor shall provide a copy of any correspondence (relating to a contractual matter) received from any Government activity involved with this contract to the PCO and ACO.
G0 3 CONTRACT HOLIDAYS
PART I - THE SCHEDULE
SECTION G - CONTRACT ADMINISTRATION DATA
SECTION G
- The prices/costs in Section B of the contract include holiday observances; accordingly, the Government will not be billed for such holidays, except when services are required by the Government and are actually performed on a holiday.
- The following days are contract holidays. New Years Day
Martin Luther King Jr, Day President's Day
Memorial Day Independence Day Labor Day Columbus Day Veterans Day Thanksgiving Day Christmas Day
- In addition to the days designated as holidays, the Government observes the following days: Any other day designated by Federal Statute
Any other day designated by Executive Order
Any other day designated by the President's Proclamation
PART I - THE SCHEDULE
SECTION H - SPECIAL CONTRACT REQUIREMENTS
SECTION H
H0 1 INCORPORATION OF SECTION K
PART I - THE SCHEDULE
SECTION H - SPECIAL CONTRACT REQUIREMENTS
SECTION H
Section K, Representations, Certifications and Other Statements of Offerors, of the solicitation is hereby incorporated by reference.
H0 2 CONTRACTOR IDENTIFICATION
PART I - THE SCHEDULE
SECTION H - SPECIAL CONTRACT REQUIREMENTS
SECTION H
- Contractor personnel and their subcontractors must identify themselves as Contractors or subcontractors during meetings, telephone conversations, in electronic messages, or correspondence related to this contract.
- Contractor-occupied facilities (on AFMC or other Government installations) such as offices, separate rooms, or cubicles must be clearly identified with Contractor supplied signs, name plates or other identification, showing that these are work areas for Contractor or subcontractor personnel.
H0 3 COMMUNICATIONS SECURITY (COMSEC) MONITORING
PART I - THE SCHEDULE
SECTION H - SPECIAL CONTRACT REQUIREMENTS
SECTION H
All communications with DoD organizations are subject to Communications Security (COMSEC) review. Contractor personnel will be aware that telecommunications networks are continually subject to interception by unfriendly intelligence organizations. The DoD has authorized the military departments to conduct COMSEC monitoring and recording of telephone calls originating from or terminating at DoD organizations. Therefore, civilian contractor personnel are advised that any time they place a call to or receive a call from a USAF organization they are subject to COMSEC procedures. The Contractor will assume the responsibility for ensuring wide and frequent dissemination of the above information to all employees dealing with official DoD information.
H 0 4 AVOIDANCE OF ORGANIZATIONAL CONFLICTS OF INTEREST (OCI)
PART I - THE SCHEDULE
SECTION H - SPECIAL CONTRACT REQUIREMENTS
SECTION H
- The parties recognize that the Contractor will play a very visible and responsible role in the fulfillment of a broad and comprehensive spectrum of requirements. This role creates access to information that is not available to the public, which: (1) might give the Contractor an unfair competitive advantage; and/or (2) creates an appearance that the Contractor has an unfair competitive advantage even if no such advantage actually exists. The technical judgment of the Contractor will influence research, development and test products, and the Contractor may play a key technical review role over other contractors' work. Both the Government and other contractors must have the utmost confidence that acquisitions are fair and that the Contractor's judgment and recommendations are objective, impartial, and independent.
- In order to prevent: (a) conflicting roles which might bias the Contractor's judgment or objectivity in meeting its duties to the Government under this and any other contract(s) with the Government; (b) an
unfair competitive advantage inuring to the Contractor under this or any other contract(s) with the Government; and (c) the appearance of an unfair competitive advantage in any Air Force acquisitions, it is agreed by the parties to this contract that the Contractor shall be restricted in its future contracting with the Government to the extent described below. The Contractor agrees to accept, and pursue to completion, all tasks identified hereunder and to ensure that its parents, subsidiaries, and affiliates do not thereafter enter into contractual agreements as prime contractors or first tier subcontractors which would create a conflict within the meaning of this clause, except as follows:
If performance of a task could cause a conflict of interest within the meaning of this clause with a contract or subcontract held by the Contractor, its parent, subsidiaries or affiliates, which pre-existed the identification of the task to the Contractor, the Contractor must disclose the conflict of interest to the Contracting Officer. If the Contracting Officer confirms that the conflict exists, the parties will consider the alternatives available to eliminate the conflict and mutually resolve it considering the relative burdens created by the prospective solutions.
- If the Contractor in the performance of this contract, assists in the preparation of a requirement, or provides information leading directly, predictably and without delay to the preparation of a requirement, it is agreed by the parties that the Contractor's parent companies, subsidiaries, and any organization with which the Contractor is affiliated through an ownership or direct financial interest shall be ineligible to participate in any competition to obtain award of a contract to perform for the Government the work described within said requirements documents.
- If the Contractor discovers an actual or potential organizational conflict of interest not previously considered or adequately mitigated under this clause, prior to any additional planning, the Contractor shall make a prompt and full disclosure in writing to the Contracting Officer. This report shall include a description of the violation and the actions the Contractor has taken or proposes to take to mitigate and avoid repetition of the violation. The Contractor shall routinely monitor its proposed business development and shall discuss any real or perceived OCI issues with the Contracting Officer and affected customers to proactively resolve and/or mitigate those potential OCI issues. After conducting such further inquiries and discussions as may be necessary, the Contracting Officer and the Contractor shall agree on appropriate corrective action, if any, or the Contracting Officer shall direct such action, subject to the terms of this contract.
- The Contractor agrees that any organization participating in the performance of this contract shall be bound as though the "Contractor" hereunder. Entities or organizations merely cooperating with the Contractor (e.g., providing information) to enable the Contractor or its agents subcontractors, or affiliates to perform shall not be deemed to be "participating" hereunder. This provision shall be incorporated in a manner to insure that such organizations, and their parents, subsidiaries, and affiliates, shall be so bound in all subcontracts, teaming arrangements, and other agreements calling for the performance of any requirements under this contract.
- OCI violations are a significant contract performance issue. Violations of this clause may have consequences ranging from award fee decrements, contract termination, suspension and debarment, or other appropriate remedies or administrative actions. This restrictions identified above applies to all work under the contract, including classified projects, and shall be in effect until and through award of any development or production contract associated with that requirement. SECTION I
NOTICE: The following contract clauses pertinent to this section are hereby incorporated by reference:
FEDERAL ACQUISITION REGULATION CONTRACT CLAUSES
52.202-01 DEFINITIONS (NOV 2013)
52.203-03 GRATUITIES (APR 1984)
52.203-05 COVENANT AGAINST CONTINGENT FEES (APR 1984)
52.203-06 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (SEP 2006)
52.203-07 ANTI-KICKBACK PROCEDURES (OCT 2010)
52.203-08 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)
52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (JAN 1997)
52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (OCT 2010)
52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (APR 2010)
52.203-14 DISPLAY OF HOTLINE POSTER(S) (DEC 2007)
52.203-15 WHISTLEBLOWER PROTECTIONS UNDER THE AMERICAN RECOVERY AND REINVESTMENT ACT OF 2009 (JUN 2010)
52.203-16 PREVENTING PERSONAL CONFLICTS OF INTEREST (DEC 2011)
52.204-02 SECURITY REQUIREMENTS (AUG 1996)
52.204-04 PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER FIBER CONTENT PAPER (MAY 2011)
52.204-09 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR PERSONNEL (JAN 2011)
52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUL 2013)
52.204-11 AMERICAN RECOVERY AND REINVESTMENT ACT--REPORTING REQUIREMENTS (JUL 2010)
52.204-12 DATA UNIVERSAL NUMBERING SYSTEM NUMBER MAINTENANCE (DEC 2012)
52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (JUL 2013)
52.209-06 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (AUG 2013)
52.209-09 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (JUL 2013)
52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS (MAY 2012)
52.210-01 MARKET RESEARCH (APR 2011)
52.211-05 MATERIAL REQUIREMENTS (AUG 2000)
52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)
- Number of calendar days is '"30'
(c) Number of days or calendar date is '30'
52.215-02 AUDIT AND RECORDS -- NEGOTIATION (OCT 2010)
52.215-08 ORDER OF PRECEDENCE--UNIFORM CONTRACT FORMAT (OCT 1997)
52.215-10 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA (AUG
2011)
52.215-11 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA-- MODIFICATIONS (AUG 2011)
52.215-12 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA (OCT 2010)
52.215-13 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA--MODIFICATIONS (OCT
2010)
52.215-14 INTEGRITY OF UNIT PRICES (OCT 2010)
52.215-15 PENSION ADJUSTMENTS AND ASSET REVERSIONS (OCT 2010)
52.215-17 WAIVER OF FACILITIES CAPITAL COST OF MONEY (OCT 1997)
52.215-18 REVERSION OR ADJUSTMENT OF PLANS FOR POSTRETIREMENT BENEFITS (PRB) OTHER THAN PENSIONS (JUL 2005)
52.215-19 NOTIFICATION OF OWNERSHIP CHANGES (OCT 1997)
52.215-21 REQUIREMENTS FOR CERTIFIED COST OR PRICING DATA AND DATA OTHER THAN CERTIFIED COST OR PRICING DATA--MODIFICATIONS (OCT 2010)
52.215-23 LIMITATIONS ON PASS-THROUGH CHARGES (OCT 2009)
52.216-07 ALLOWABLE COST AND PAYMENT (JUN 2013)
52.216-08 FIXED FEE (JUN 2011)
52.216-10 INCENTIVE FEE (JUN 2011)
52.216-11 COST CONTRACT -- NO FEE (APR 1984)
52.216-16 INCENTIVE PRICE REVISION -- FIRM TARGET (OCT 1997)
52.216-17 INCENTIVE PRICE REVISION -- SUCCESSIVE TARGETS (OCT 1997)
52.216-18 ORDERING (OCT 1995)
52.217-08 OPTION TO EXTEND SERVICES (NOV 1999)
Period of time. ''ten (10) days immediately preceding base period, option period, or award term period.''
52.222-01 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997)
52.222-02 PAYMENT FOR OVERTIME PREMIUMS (JUL 1990)
52.222-04 CONTRACT WORK HOURS AND SAFETY STANDARDS ACT -- OVERTIME
COMPENSATION (JUL 2005)
52.222-19 CHILD LABOR--COOPERATION WITH AUTHORITIES AND REMEDIES (JAN 2014)
52.222-20 WALSH-HEALEY PUBLIC CONTRACTS ACT (OCT 2010)
52.222-21 PROHIBITION OF SEGREGATED FACILITIES (FEB 1999)
52.222-26 EQUAL OPPORTUNITY (MAR 2007)
52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (FEB
1999)
52.222-35 EQUAL OPPORTUNITY FOR VETERANS (SEP 2010)
52.222-36 AFFIRMATIVE ACTION FOR WORKERS WITH DISABILITIES (OCT 2010)
52.222-37 EMPLOYMENT REPORTS ON VETERANS (SEP 2010)
52.222-41 SERVICE CONTRACT ACT OF 1965 (NOV 2007)
52.222-43 FAIR LABOR STANDARDS ACT AND SERVICE CONTRACT ACT -- PRICE ADJUSTMENT (MULTIPLE YEAR AND OPTION CONTRACTS) (SEP 2009)
52.222-50 COMBATING TRAFFICKING IN PERSONS (FEB 2009)
52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (AUG 2013)
52.223-06 DRUG-FREE WORKPLACE (MAY 2001)
52.223-15 ENERGY EFFICIENCY IN ENERGY-CONSUMING PRODUCTS (DEC 2007)
52.223-16 IEEE 1680 STANDARD FOR THE ENVIRONMENTAL ASSESSMENT OF PERSONAL COMPUTER PRODUCTS (DEC 2007)
52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (AUG 2011)
52.224-01 PRIVACY ACT NOTIFICATION (APR 1984)
52.224-02 PRIVACY ACT (APR 1984)
52.225-05 TRADE AGREEMENTS (NOV 2013)
52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (JUN 2008)
52.227-01 AUTHORIZATION AND CONSENT (DEC 2007)
52.227-02 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (DEC 2007)
52.227-03 PATENT INDEMNITY (APR 1984)
52.227-11 PATENT RIGHTS -- OWNERSHIP BY THE CONTRACTOR (DEC 2007)
52.228-05 INSURANCE -- WORK ON A GOVERNMENT INSTALLATION (JAN 1997)
52.228-07 INSURANCE -- LIABILITY TO THIRD PERSONS (MAR 1996)
52.229-03 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)
52.232-01 PAYMENTS (APR 1984)
52.232-07 PAYMENTS UNDER TIME-AND-MATERIALS AND LABOR-HOUR CONTRACTS (AUG
2012)
52.232-08 DISCOUNTS FOR PROMPT PAYMENT (FEB 2002)
52.232-09 LIMITATION ON WITHHOLDING OF PAYMENTS (APR 1984)
52.232-16 PROGRESS PAYMENTS (APR 2012)
52.232-17 INTEREST (OCT 2010)
52.232-18 AVAILABILITY OF FUNDS (APR 1984)
52.232-20 LIMITATION OF COST (APR 1984)
52.232-22 LIMITATION OF FUNDS (APR 1984)
52.232-24 PROHIBITION OF ASSIGNMENT OF CLAIMS (JAN 1986)
52.232-25 PROMPT PAYMENT (JUL 2013)
52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER--SYSTEM FOR AWARD MANAGEMENT (JUL 2013)
52.233-01 DISPUTES (JUL 2002)
52.233-03 PROTEST AFTER AWARD (AUG 1996)
52.233-04 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)
52.236-01 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)
52.239-01 PRIVACY OR SECURITY SAFEGUARDS (AUG 1996)
52.242-01 NOTICE OF INTENT TO DISALLOW COSTS (APR 1984)
52.242-03 PENALTIES FOR UNALLOWABLE COSTS (MAY 2001)
52.242-04 CERTIFICATION OF FINAL INDIRECT COSTS (JAN 1997)
52.242-13 BANKRUPTCY (JUL 1995)
52.243-01 CHANGES -- FIXED-PRICE (AUG 1987)
52.243-02 CHANGES -- COST-REIMBURSEMENT (AUG 1987) (APR 1984)
52.243-03 CHANGES -- TIME-AND-MATERIALS OR LABOR-HOURS (SEP 2000)
52.243-04 CHANGES (JUN 2007)
52.243-06 CHANGE ORDER ACCOUNTING (APR 1984)
52.243-07 NOTIFICATION OF CHANGES (APR 1984)
52.244-02 SUBCONTRACTS (OCT 2010)
52.244-05 COMPETITION IN SUBCONTRACTING (DEC 1996)
52.244-06 SUBCONTRACTS FOR COMMERCIAL ITEMS (DEC 2013)
52.245-01 GOVERNMENT PROPERTY (APR 2012)
52.246-17 WARRANTY OF SUPPLIES OF A NONCOMPLEX NATURE (JUN 2003)
52.246-18 WARRANTY OF SUPPLIES OF A COMPLEX NATURE (MAY 2001)
52.246-20 WARRANTY OF SERVICES (MAY 2001)
52.247-63 PREFERENCE FOR U.S.-FLAG AIR CARRIERS (JUN 2003)
52.248-01 VALUE ENGINEERING (OCT 2010)
52.249-02 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR
2012)
52.249-04 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (SERVICES)(SHORT FORM) (APR 1984)
52.249-06 TERMINATION (COST-REIMBURSEMENT) (MAY 2004)
52.249-08 DEFAULT (FIXED-PRICE SUPPLY AND SERVICE) (APR 1984)
52.249-14 EXCUSABLE DELAYS (APR 1984)
52.251-01 GOVERNMENT SUPPLY SOURCES (APR 2012)
52.253-01 COMPUTER GENERATED FORMS (JAN 1991)
52.211-15 DEFENSE PRIORITY AND ALLOCATION REQUIREMENTS (APR 2008)
SECTION I
This is a rated order certified for national defense, emergency preparedness, and energy program use, and the Contractor shall follow all the requirements of the Defense Priorities and Allocations System regulation (15 CFR 700).
52.217-09 OPTION TO EXTEND THE TERM OF THE CONTRACT (MAR 2000) (TAILORED)
SECTION I
- The Government may extend the term of this contract by written notice to the Contractor within ten (10) calendar days prior to the end of base period or any option periods, provided that the Government gives the Contractor a preliminary written notice of its intent to extend at least sixty (60) days before the contract expires. The preliminary notice does not commit the Government to an extension.
- If the Government exercises this option, the extended contract shall be considered to include this option clause.
- The total duration of this contract, including the exercise of any options under this clause, shall not exceed seven (7) years including all option periods.
52.222-42 STATEMENT OF EQUIVALENT RATES FOR FEDERAL HIRES (MAY 1989)
SECTION I
In compliance with the Service Contract Act of 1965, as amended, and the regulations of the Secretary of Labor (29 CFR Part 4), this clause identifies the classes of service employees expected to be employed under the contract and states the wages and fringe benefits payable to each if they were employed by the contracting agency subject to the provisions of 5 U.S.C. 5341 or 5332.
SECTION J - LIST OF ATTACHMENTS
DOCUMENT
PGS
DATE
TITLE
ATTACHMENT 1
41
03 FEB
PERFORMANCE WORK STATEMENT (PWS)
ATTACHMENT 2
5
16 MAY
NOSB LABOR RATES/CATEGORY DESCRIPTIONS
ATTACHMENT 3
2
03 FEB
NOSB CONTRACT SECURITY CLASSIFICATION SPECIFICATION (DD254)
[Note to UMUC BMGT 482 students: the attachments are not relevant and are not actually provided]
